DIVISION 1 GENERAL REQUIREMENTS SECTION SUBMITTAL PROCEDURES
|
|
- Ferdinand Emery Bailey
- 5 years ago
- Views:
Transcription
1 DIVISION 1 GENERAL REQUIREMENTS SECTION PART 1 - GENERAL 1.1 SUMMARY A. This section includes administrative and procedural requirements for submittals required for performance of the work, including but not limited to the following:. 1. Submittal schedule 2. Contractor s construction schedule including schedule of values. 3. Daily construction reports 4. Shop Drawings 5. Product Data 6. Samples 7. Operating/Maintenance Manuals 8. Quality assurance submittals 9. Performance and Payment Bonds 10. Insurance Certificates 11. Application for payment 12. Certified payroll reports 13. MBE/WBE reports 14. Partial and Final receipt of Payment and Release Forms 15. Affidavit Compliance with Prevailing Wage Laws 16. Record Drawings 1.2 DEFINITIONS A. Coordination Drawings show the relationship and the integration of different construction elements that require careful coordination during fabrication or installation to fit in the space provided or to function as intended. B. Preparation of coordination drawing is specified in Division 1 Section Coordination and may include components previously shown on Shop Drawings of Product Data. C. Field Samples are full size physical examples erected to illustrate finishes, coatings, or finish materials. Field Samples are used to establish the standard by which the work will be judged. Samples may not be returned to the contractor. D. Mockups are full size assemblies for review of construction, coordination, testing, or operation; they are not samples. Mockups may not be returned to the contractor. 1.3 A. Work included: To insure that the specified products are furnished and installed in accordance with the design intent, these procedures have been established in advance for electronic and hard copy submittals for review by the Architect/Engineer. B. The contractor shall comply with the General and Supplemental Conditions and other applicable sections of the Contract Documents. The contractor shall submit, with such promptness as to cause no delay in his work or in that of any other contractors, all required submittals. Coordinate the preparation and processing of submittals with the performance of construction activities. 13-HC
2 Transmit each submittal sufficiently in advance of performance of construction activities to avoid delay. 1. Coordinate each submittal with fabrication, purchasing, testing, delivery, other submittals, and related activities that require sequential activity. 2. Coordinate transmittal of different types of submittals for related elements of the Work so processing will not be delayed by the need to review submittals concurrently for coordination. a. The Architect/Engineer reserves the right to withhold action on a submittal requiring coordination with other submittals until all related submittals are received. C. Processing: To avoid the need to delay installation as a result of the time required to process submittals, allow sufficient time for submittal review, including time for re-submittals if necessary. 1. Allow 2 weeks for the initial review. Allow additional time if the Architect/Engineer must delay processing to permit coordination with subsequent submittals. 2. If an intermediate submittal is necessary, process the same as the initial submittal. 3. Allow 2 weeks for reprocessing each submittal. 4. No extension of time will be authorized because of failure to transmit submittals to the Construction Manager and Architect/Engineer sufficiently in advance of the work to permit processing. D. The official date of the submittal shall be the later receipt date of either the Hard Copy or the Electronic Copy of the submittal whichever is latest. 1.4 SHOP DRAWINGS A. After acceptance of the Contractor s Construction Schedule, the contractor shall prepare a complete schedule of submittals. Submit the schedule within 25 days of the Notice to Proceed. This schedule will be used to set up the electronic monitoring and management of the timely submission and review of all submittals and shop drawings for this project. B. One hard copy and one electronic copy of each shall be submitted as indicated below. The contractor shall be responsible to follow the procedure as indicated. Submit newly prepared information drawn accurately to scale. Highlight, encircle, or otherwise indicate deviations from the Contract Documents. Do not reproduce Contract Documents or copy standard information as the basis of Shop Drawings. Standard information without specific reference to the Project is not a Shop Drawing. Shop Drawings include fabrication and installation drawings, setting diagrams, schedules, patterns, templates, and similar drawings. Include the following information: 1. Dimensions 2. Identification of products and materials included by sheet and detail number 3. Compliance with specified standards 4. Notation of coordination requirements 5. Notation of dimensions established by field measurements C. If electronic submission of Shop Drawings is not possible, the Contractor shall submit eight (8) copies (hard copies) to the offices of the Architect/Engineer. D. Procedures(Hard Copy) 1. Contractor shall submit 1 (one) copy of each sheet of shop drawings. 2. Standard mass produced items may be catalog cuts. Submit 1 (one) copy of each. 3. Mock-ups, samples, or on-site sample panels shall be as described herein or as required within the specification section for a particular product, material, application, erection, or installation. E. Procedures(Electronic Copy) HC1-033
3 1. At the pre-construction meeting, the contractor will be given a username and password to gain access to the submittal page on the MKC Web Site. All shop drawing submittals shall be named according to the specification section number the submittal is requested. Additional submittals will contain -1 or -2 etc. following the section number ( , ). 2. Contractor shall upload the electronic copy of the shop drawing in PDF format to the MKC FTP site utilizing the username and password supplied to the contractor at the preconstruction meeting. If any changes, comments, or modifications are required after the contractor has posted documents to the FTP site, the contractor shall resubmit the revised document in similar fashion to the MKC FTP site. Should the contractor have any questions or problems with this process, contact MKC at or to esdquestions@mkcinc.com. 3. The Contractor shall issue an to the project team stating that a shop drawing has been posted to the FTP site. 4. MKC will issue an to the contractor informing them that we have received the submittal. MKC will post the submittal to the MKC web site for access by the owner and contractor. The Contractor shall check the shop drawing log at this location for the status of the shop drawing review. 5. The Contractor shall download the reviewed shop drawing and make all of the necessary copies for distribution. F. Reviews: The review of shop drawings, cut sheets, and schedules by the Architect/Engineer will be general and shall be understood to mean that the Architect/Engineer has no objection to the use of materials or processes shown. The Architect/Engineer's review shall not relieve the Contractor of responsibility for errors omissions and deviations from the contract requirements. 1.5 SAMPLES A. Submit full-size, fully fabricated Samples cured and finished as specified and physically identical with the material or product proposed. Samples include partial sections of manufactured or fabricated components, cuts or containers of materials, color range sets, and swatches showing color, texture, and pattern. 1.6 QUALITY ASSURANCE DOCUMENT A. Submit quality-control submittals, including design data, certifications, manufacturer's instructions, manufacturer's field reports, and other quality-control submittals as required under other Sections of the Specifications. 1.7 OPERATING AND MAINTENANCE MANUALS AND WARRANTIES A. Submit all required manufacturer s operating instructions, maintenance/service manuals and warranties in accordance with the General and Supplemental Conditions and other sections of the Contract Documents. PART 2 - PRODUCTS 2.1 SHOP DRAWINGS AND COORDINATION DRAWINGS A. Shop Drawings: Make all Shop Drawings accurately to a scale sufficiently large enough to show all pertinent aspects of the item and its method of connection to the Work. 13-HC
4 B. Contractor's approval: All shop drawings, cut sheets, and schedules submitted shall bear the stamp and date of approval of contractor as evidence that the information has been checked and approved by the contractor. Correction of dimensions, location of various item encroachments on the work of other contractors or subcontractors or variations from the requirements of the Contract Documents shall be made or corrected by the Contractor. Failure to approve, note and correct submissions of shop and coordination drawings will result in their immediate return. C. Re-submissions of shop drawings: Re-submission of any shop drawing, product data, or samples, the contractor shall make any corrections or changes noted on previous submittals and re-submit as specified for the initial submittal by utilizing a R1 affixed to the end of the file name (i.e r1.pdf). The Architect/Engineer will review only that portion of the resubmitted shop drawing that was so noted on the previous submittal. The Contractor is not to revise any other portion of the re-submittal. If the Contractor wishes to revise any portion of a reviewed submittal, it must be clearly noted and treated as a new submittal. The Architect/Engineer is not obligated to review resubmitted material. D. The Contractor shall reference the details on shop drawings to the sheet, details, schedule, or room numbers shown on the Construction Documents. E. When submitting manufacturer s standard schematic drawings and diagrams, the Contractor shall modify the documents to delete information which is not applicable to the Work and supplement the standard information specifically applicable to the Work. F. Mock-ups will be removed by the Contractor when directed by the Architect/Engineer. G. The Contractor shall notify the Architect/Engineer in writing at the time of the submittal of any deviations in the submittal from the Construction Documents. Review of any submittal containing a deviation from the Construction Documents does not relieve the Contractor of complying with the Construction Documents in all respects unless the deviation is specifically approved in writing by the Architect/Engineer. H. The Contractor shall not begin fabrication until all specified submittal procedures have been fulfilled. 2.2 SAMPLES A. Accuracy of samples: Samples shall be of the precise article proposed to be furnished B. Quantity of samples required: Unless otherwise specified, submit all samples as specified within each specification section. 2.3 SUBSTITUTIONS A. Review required: The Contract is based on the standards of quality established in the Contract Documents. All products proposed for use, including those specified by required attributes and performance shall require review by the Architect/Engineer before being incorporated into the Work. Do not substitute materials, equipment, or methods unless such substitutions have been specifically approved for this Work by the Architect/Engineer. B. "Or Equal": Where the phrase "or equal" or "or equal as approved by the Architect/Engineer" occurs in the Contract Documents, do not assume that materials, equipment or methods will be approved as equal unless the item has been specifically approved for this Work by the Architect/Engineer. The decision of the Architect/Engineer shall be final HC1-033
5 PART 3 - EXECUTION 3.1 ARCHITECTS REVIEW A. General: review by the Architect/Engineer shall not be construed as a complete check, but only the general method of construction and detailing is satisfactory. Review shall not relieve the Contractor from responsibility for errors which may exist. B. Authority to proceed: The notations "Reviewed" or "Furnish as Corrected" authorize the Contractor to proceed with fabrication, purchase, or both, of the items so noted, subject to the revisions, if any, required by the Architect/Engineer's review comments. The notations Submit Specified Item or Rejected do not authorize the contractor to proceed but rather requires the contractor to resubmit the shop drawing in compliance with the construction documents. C. Revisions: Make all revisions required by the Architect/Engineer. If the Contractor considers any required revisions to be a change, they shall so notify the Architect/Engineer as provided for under "Changes" in the General Conditions. Show each drawing revision by number, date, and subject in a revision block on the drawing. Make only those revisions directed or reviewed by the Architect/Engineer. D. Revisions after review: When a submittal has been reviewed by the Architect/Engineer, resubmittal for substitution of materials or equipment will not be considered unless accompanied by an acceptable explanation as to why the substitution is necessary. 3.2 ELECTRONIC SUBMITTAL REVIEW A. This Electronic Copy submittal process is internet-based and requires no special software or downloading of programs of any type. However this process does require the contractor to have the ability to upload and download documents in a PDF format to the locations indicated herein. This process also requires the user to agree to MKC s Terms and Conditions of use. B. Software to aid in creation of PDF documents can be acquired through the free Open Office or other commercial software of the contractor s choice. C. Submittals Initiation & Upload 1. The submittal shall be uploaded to the MKC FTP site. 2. All uploaded submittals shall include a transmittal with the following information a. Company Name b. Responsible Individuals Name c. Company Address d. Company Telephone Number e. Responsible Individuals Phone Number or Extension f. Responsible Individuals Address g. Standard transmittal information including but not limited to the description of the transmitted item, actions taken, project name etc. h. Specification section number followed by -1, -2 or -3 etc. 3. Creation of the up loadable file for the MKC FTP site. a. Create one (1) PDF submittal document with the file name provided for each submittal. Each submittal document shall include all pages associated with that submittal. 4. Upload the Submittal to the MKC FTP site a. Using Internet Explorer, enter the following address: ftp:// b. Enter the username and password that you are given at the pre-construction meeting. Click on the log-on button. If you are using IE 6 it will open directly to the correct page for you to upload (paste) your submittal. If you are using IE 7 or IE 13-HC
6 8, you will click on Page and then click on Open FTP site in Windows Explorer. You will need to enter the username and password a second time that will open the folder in the proper location for your file to be uploaded. c. Upload your appropriately named PDF file into the established project sub-folder on the server, the usual method is to copy and paste your PDF file into the MKC FTP site project folder. d. Files larger than 2MB should be zipped before uploading them to improve the file transfer process. D. At the successful completion of the upload, send an the MKC project team to notify them that an electronic shop drawing has been posted. Failure to comply will result in delay of the process to review the submittal. Send the to [project-job-number@mkcinc.com]. E. Once the shop drawing is uploaded to the MKC FTP Site Submittals ( page, the Architect/Engineer will send an to the contractor stating that a shop drawing has been received and posted on the web site. It is the contractor s responsibility to check the web site for the final reviewed shop drawing. The final reviewed electronic shop drawing can then be downloaded, printed or saved to the location selected by the Contractor. The contractor shall print the necessary copies for distribution as required. F. During the review of the electronic submittal, the Architect/Engineer will identify any needed notations or revision marks and will affix an electronic stamp indicating that the shop drawing is either Reviewed, Furnish as Corrected, Revise and Resubmit, Submit Specified Item or Rejected. The Architect/Engineer will then update the electronic copy on the MKC website. If the shop drawing has been noted as Reviewed or Furnish as Corrected, the indicated corrections or revisions shall be addressed and followed by the contractor. If the shop drawing has been noted as Rejected Submit Specified Item or Revise and Resubmit, the contractor shall resubmit to comply with the construction documents using the same specification number used on the rejected shop drawing submittal followed by -R1 or -R2 etc., signifying the resubmitted attempt. G. MKC will maintain the shop drawing log, indicating receipt dates, review dates, review status and distribution dates. Submittal status is color coded on the shop drawing log as follows: H. 1. Yellow: Received New (RN) 2. Orange: Sent to Consultant (STC) 3. Light Green: Back From Consultant (BFC) 4. Magenta: Return to Sender For Revision (RSFR) 5. Dark Green: Complete (COM) I. The shop drawing log can be viewed on the MKC Web site at the following address: The shop drawing log can be viewed by the owner, the contractor, the construction manager at any time with the appropriate username and password. The log cannot be modified by anyone but MKC personnel. END OF SECTION HC1-033
A. Action Submittals: Written and graphic information that requires Engineer's responsive action.
SECTION 01330 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 1 Specification
More informationEast Central College
SECTION 013300 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification
More informationSection Meetings Section Material and Equipment. None Required
January 2000 Page 1 of 8 PART 1 GENERAL 1.01 OTHER CONTRACT DOCUMENTS 1.02 DESCRIPTION OF WORK 1.03 RELATED WORK PART 2 PRODUCTS The General Conditions of the Contract, General Requirements and Supplemental
More informationSECTION SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES
SECTION 01 33 23 SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES PART 1 GENERAL 1.1 DESCRIPTION A. This specification defines the general requirements and procedures for submittals. A submittal is information
More informationA. Action Submittals: Written and graphic information that requires Architect's responsive action.
SECTION 01330 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 1 Specification
More informationDIVISION 1 - GENERAL REQUIREMENTS SECTION SUBMITTALS
DIVISION 1 - GENERAL REQUIREMENTS SECTION 01300 - SUBMITTALS PART 1 - GENERAL 1.1 STIPULATIONS A. The section "Special Requirements" forms a part of this section by this reference thereto and shall have
More informationA. This section specifies procedural requirements for Shop Drawings, product data, samples, and other miscellaneous Work-related submittals.
SECTION 01300 PART 1 GENERAL 1.1 SECTION INCLUDES A. Description of Requirements B. Submittal Procedures C. Specific Submittal Requirements D. Action on Submittals E. Repetitive Review 1.2 DESCRIPTION
More informationSECTION SUBMITTALS PART 1 - GENERAL 1.01 RELATED DOCUMENTS
SECTION 01300 SUBMITTALS PART 1 - GENERAL 1.01 RELATED DOCUMENTS A. Drawings and general provisions of Contract, including General and Supplementary Conditions and other Division-1 Specification Sections,
More informationUNION COUNTY VOCATIONAL-TECHNICAL SCHOOLS West Hall Addition Project Raritan Road, Scotch Plains, NJ
SECTION 013300 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 1 General
More informationSECTION SUBMITTAL PROCEDURES
SECTION 01330 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 1 Specification
More informationMISSISSIPPI STATE UNIVERSITY Office of Planning Design and Construction Administration
SECTION 01 340 - SHOP DRAWINGS, PRODUCT DATA AND SAMPLES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other
More informationTCC/SHORE TRANSIT BUS MAINTENANCE FACILITY - PHASE II
SECTION 013300 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification
More informationSECTION SUBMITTAL PROCEDURES
SECTION 013300 PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification Sections, apply
More informationJEFFERSON LAB TECHNICAL ENGINEERING & DEVELOPMENT FACILITY (TEDF ONE) Newport News, Virginia
BULLETIN NO. 6 TO THE PLANS AND SPECIFICATIONS FOR JEFFERSON LAB TECHNICAL ENGINEERING & DEVELOPMENT FACILITY (TEDF ONE) Newport News, Virginia EwingCole Architects.Engineers.Interior Designers.Planners
More informationUCCS University Hall Fire Sprinkler System Upgrade March 1, 2011 RTA SECTION SUBMITTAL PROCEDURES PART 1 - GENERAL
SECTION 013300 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification
More informationSECTION SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS
SECTION 01 33 00 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification
More informationNORTHWESTERN UNIVERSITY PROJECT NAME JOB # ISSUED: 03/29/2017
SECTION 01 3300 - SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification
More informationSECTION A. RFI: Request from Contractor seeking interpretation, information, or clarification of the Contract Documents.
SECTION 01 3000 PART 1 GENERAL 1.1 SECTION INCLUDES A. Electronic document submittal service. B. Preconstruction meeting. C. Submittals for review, information, and project closeout. D. Submittal procedures.
More informationTaylor County July 2011 SECTION SHOP DRAWINGS, WORKING DRAWINGS AND SAMPLES
SECTION 01340 SHOP DRAWINGS, WORKING DRAWINGS AND SAMPLES PART 1 - GENERAL 1.1 REQUIREMENTS INCLUDED A. Contractor shall submit to the Architect/Engineer for review and exception, if any, such working
More informationSECTION SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES
SECTION 01334 SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES PART 1 GENERAL 1.01 SUMMARY A. Submit to the ENGINEER for review, such working drawings, shop drawings, test reports and data on materials and equipment
More informationJacksonville District Master
-01 33 00 (April 2006) From USACE / NAVFAC / AFCESA UFGS UNIFIED FACILITIES GUIDE SPECIFICATIONS Revised thoughout - changes not indicated by CHG tags SECTION TABLE OF CONTENTS DIVISION 01 - GENERAL REQUIREMENTS
More informationSECTION ADMINISTRATIVE REQUIREMENTS SECTION ADMINISTRATIVE REQUIREMENTS
PART 1 GENERAL 1.01 SECTION INCLUDES A. Project Coordination. B. Preconstruction meeting. C. Progress meetings. D. Preinstallation conferences. E. Requests for information (RFI). F. Coordination drawings.
More informationSECTION SUBMITTAL PROCEDURES
SECTION 01330 SUBMITTAL PROCEDURES PART 1 - GENERAL 1.1 DESCRIPTION A. Scope: 1. CONTRACTOR shall provide submittals in accordance with the General Conditions as modified by the Supplementary Conditions,
More informationSECTION SUBMITTALS. A. PART A and DIVISION 1 of PART B are hereby made a part of this SECTION.
SECTION 013300 PART 1 GENERAL 1.01 GENERAL REQUIREMENTS A. PART A and DIVISION 1 of PART B are hereby made a part of this SECTION. B. Examine all conditions as they exist at the project prior to submitting
More informationSECTION CONTRACTOR SUBMITTALS. A. All submittals by the CONTRACTOR shall be submitted to the ENGINEER.
SECTION 01300 - PART 1 - GENERAL 1.1 GENERAL A. All submittals by the CONTRACTOR shall be submitted to the ENGINEER. B. Unless otherwise noted, within 14 days after the date of commencement as stated in
More informationAnswer: Qualification statement should be provided with the bid.
Little Diversified Architectural Consulting, Inc. 5815 Westpark Drive Charlotte, North Carolina 28217 Phone: 704-525-6350 Fax: 704-561-8700 Lincoln County Probation Renovation 208 N. Government Street
More information2016 CDM Smith All Rights Reserved July 2016 SECTION PROJECT MEETINGS
PART 1 GENERAL 1.01 REQUIREMENTS INCLUDED SECTION 01 20 00 PROJECT MEETINGS A. Construction Manager shall schedule and administer pre-construction meeting, periodic progress meetings, and specially called
More informationSECTION ADMINISTRATIVE REQUIREMENTS
PART 1 GENERAL 1.01 SECTION INCLUDES A. Electronic document submittal service. B. Preconstruction meeting. C. Progress meetings. D. Construction progress schedule. E. Coordination drawings. SECTION 013000
More informationSTANDARD SPECIFICATIONS SECTION SUBMITTAL PROCEDURES
STANDARD SPECIFICATIONS SECTION 01330 SUBMITTAL PROCEDURES PART 1 GENERAL 1.1 DESCRIPTION A. Section includes general requirements and procedures related to preparation and transmittal of Submittals to
More informationWorking Drawing Manual
Working Drawing Manual 2012 Table of Contents Section 1 Working Drawing Types... 1 1.1 General... 1 Section 2 Processing Steps... 1 2.1 Project Manager... 1 2.2 Engineering Document Unit... 2 2.3 Contractor...
More informationDWG, Inc. Coastal Carolina University State Project No. Consulting Engineers HTC Arena Lighting H17-N112-JM
SECTION 011000 SUMMARY PART 1 - GENERAL 1.1 SUMMARY A. This Section includes the following: 1. Work covered by the Contract Documents. 2. Work under other contracts. 3. Use of premises. 4. Specification
More informationSECTION SUBMITTAL PROCEDURES
SECTION 01 33 00 SUBMITTAL PROCEDURES PART 1 GENERAL 1.1 SUMMARY A. Section Includes. 1. Submittal procedures. 2. Product data. 3. Shop drawings. 4. Samples. 5. Design data. 6. Test reports. 7. Certificates.
More informationSHOP DRAWINGS, PRODUCT DATA, AND SAMPLES
SECTION 01340 SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES PART 1 GENERAL 1.01 SUMMARY A. Section Includes: Shop drawings, manufacturer's catalog cuts, product data, samples, and attached Shop Drawing/ Catalog
More informationSECTION SCHEDULE OF VALUES PART 1 - GENERAL 1.1 THE REQUIREMENT A. This Section defines the process whereby the Schedule of Values (Lump Sum
SECTION 013201 - SCHEDULE OF VALUES PART 1 - GENERAL 1.1 THE REQUIREMENT A. This Section defines the process whereby the Schedule of Values (Lump Sum Pay Unit price breakdown) shall be developed and ultimately
More information.2 Accompany all submissions with a transmittal letter, in duplicate, containing:.4 Specification Section number for each submittal
City of Winnipeg Brady Road Landfill Site Section 01300 New Entrance and Scale Facility Page 1 of 4 SUBMITTALS 1. SHOP DRAWINGS 1.1 General.1 Arrange for the preparation of clearly identified Shop Drawings
More informationPROJECT TITLE PROJECT NO: CONTRACT TITLE UNIVERSITY OF CALIFORNIA, DAVIS CITY, CALIFORNIA
If project is not administered in PRISM, coordinate use of Exhibit 6 submittal schedule with this section. SECTION 01 33 23 SHOP DRAWINGS, PRODUCT DATA AND SAMPLES PART 1 - GENERAL 1.1 REQUIREMENTS INCLUDED
More informationINDEX OF SPECIFICATIONS SECTION F SPECIAL CONDITIONS DIVISION 1 - GENERAL REQUIREMENTS:
INDEX OF SPECIFICATIONS SECTION F SPECIAL CONDITIONS DIVISION 1 - GENERAL REQUIREMENTS: 013300 SUBMITTAL PROCEDURES 018116 CONSTRUCTION WASTE MANAGEMENT DIVISION 2 EXISTING CONDITIONS: 023000 EARTHWORK
More informationSECTION SHOP DRAWINGS, PRODUCT DATA, AND SAMPLES
SECTION 01 33 23 - SHOP DRAWINGS, PRODUCT DATA, AND PART 1 - GENERAL 1.1 SUMMARY A. Products include, but are not limited to, the following construction submittals: 1. Shop Drawings. 2. Product Data. 3.
More information2017 CDM Smith All Rights Reserved November 2016 SECTION PROJECT MANAGEMENT INFORMATION SYSTEM (PMIS)
ATTACHMENT 5, CONTRACT 13, ADDENDUM 3 2017 CDM Smith 14955-109447 SECTION 01725 PROJECT MANAGEMENT INFORMATION SYSTEM (PMIS) PART 1 GENERAL 1.01 DESCRIPTION A. The Owner and Contractor shall utilize the
More informationSUBCONTRACTORS PROCEDURES MANUAL EXHIBIT A.15 SAMPLE MANUAL ONLY FINAL MANUAL WILL BE CUSTOMIZED FOR GREAT WOLF LODGE
(Project) (Date) (Location) Turner Job # (TBD) Item No. 15 SUBCONTRACTORS PROCEDURES MANUAL EXHIBIT A.15 SAMPLE MANUAL ONLY FINAL MANUAL WILL BE CUSTOMIZED FOR GREAT WOLF LODGE (Location) TURNER CONTRACT
More informationSUBMITTAL PROCEDURES
SUBMITTAL PROCEDURES PART 1 GENERAL The ASPA Project Engineer (APE) may request submittals in addition to those specified when deemed necessary to adequately describe the work covered in the respective
More informationSECTION CLOSEOUT SUBMITTALS SECTION CLOSEOUT SUBMITTALS
PART 1 GENERAL 1.01 SECTION INCLUDES A. Project Record Documents. B. Operation and Maintenance Manuals. C. Warranties and bonds. 1.02 RELATED REQUIREMENTS SECTION 01 78 00 A. Section 01 30 00 - Administrative
More information01100 SUMMARY OF WORK
Lambert..STL Airport Uve Animal Facility- World Trade Center- St. Louis, Missouri 01100 SUMMARY OF WORK PART 1.. DESCRIPTION a. General: The work to be completed consists of fabrication, deliver, and installation
More informationPROCEDURE FOR PROCESSING WORKING DRAWINGS
PROCEDURE FOR PROCESSING WORKING DRAWINGS MAY 2005 Procedure for Processing Working Drawings GENERAL: The procedure for the review and processing of working drawings provide for two primary types of drawings,
More informationSECTION 2 GENERAL REQUIREMENTS
SECTION 2 GENERAL REQUIREMENTS 2-1 ENGINEER REQUIRED: All plans and specifications for Improvements which are to be accepted for maintenance by the County and private, on-site drainage and grading shall
More informationWorking Drawing Procedure
Working Drawing Procedure June 2007 Prepared by Structural Engineering & Construction Services 1.0 Working Drawing Procedure 1.1 General There are two primary types of working drawings, those requiring
More informationCloud Based Plan Review Process (Applicant)
1 Cloud Based Plan Review Process (Applicant) Organize Documentation Process Overview Upload Documents To Mercer Island FTP Site No Initial Submittal? Yes Intake Screening Approved? CST will inform you
More informationsubmittals 1s e c t i o n
Architectural Woodwork Standards submittals 1s e c t i o n SECTION 1 introductory Information Introduction...25 What to Expect...25 Purpose...25 Level of Detail...25 Approvals...25 Scheduling...25 The
More informationSECTION SUBMITTALS
SECTION 01300 SUBMITTALS PART 1- GENERAL 1.01 SCOPE OF WORK A. This Section specifies the general methods and requirements of submissions applicable to Shop Drawings, Product Data, Samples and Operations
More informationWhat Are Submittals?
Introduction Overview of the Submittal Process Comparison of AIA with ConsensusDOCS Architect and Contractor Obligations FAR Requirements State Licensing Requirements 1 What Are Submittals? Submittals
More informationNORTHWESTERN UNIVERSITY PROJECT NAME JOB # ISSUED: 12/12/2018
SECTION 01 7839 - PROJECT RECORD DOCUMENTS GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification
More information***************************************************************************** DRAFT UFGS- 01 XX XX (FEB 2014)
DRAFT UFGS- 01 XX XX (FEB 2014) ------------------------ Drafting Activity: USACE UNIFIED FACILITIES GUIDE SPECIFICATION SECTION TABLE OF CONTENTS DIVISION 01 GENERAL REQUIREMENTS SECTION 01 XX XX (FEB
More informationA. Section includes administrative and procedural requirements for project record documents, including the following:
SECTION 017839 - PROJECT RECORD DOCUMENTS PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01
More informationThis specification describes the general requirements for Engineering Services provided to Vale.
1/9 1.0 PURPOSE This specification describes the general requirements for Engineering Services provided to Vale. 2.0 GENERAL For the purposes of this document, the Engineering Consultant shall be referred
More informationUNIFIED FACILITIES GUIDE SPECIFICATIONS ************************************************************************** SECTION TABLE OF CONTENTS
USACE / NAVFAC / AFCEC / NASA UFGS-01 33 00 (May 2011) Change 9-08/17 ----------------------------- Preparing Activity: NASA Superseding UFGS-01 33 00 (February 2011) UNIFIED FACILITIES GUIDE SPECIFICATIONS
More informationCITY OF RICHMOND SUBDIVISION PLAT AND PUBLIC INFRASTRUCTURE SUBMITTAL, REVIEW AND APPROVAL PROCEDURES
SUBDIVISION PLAT AND PUBLIC INFRASTRUCTURE SUBMITTAL, REVIEW AND APPROVAL PROCEDURES CITY OF RICHMOND 112 JACKSON STREET RICHMOND, TEXAS 77469 PHONE: 281-232-6871 FAX: 281-238-1215 CITY OF RICHMOND PUBLIC
More informationUNIFIED FACILITIES GUIDE SPECIFICATIONS *************************************************************************** SECTION
USACE / NAVFAC / AFCEC / NASA UFGS-01 33 00.05 20 (May 2014) Change 1-09/15 Change 2-12/15 Change 3-09/16 ----------------------------------- Preparing Activity: NAVFAC Superseding UFGS-01 33 00.05 20
More informationSPECIFICATIONS FOR NEW UNDERGROUND RESIDENTIAL DISTRIBUTION SYSTEMS
Page: 4-1 4.0 URD Process and Documentation Requirements 4.1 Process Steps The process of developing underground distribution facilities in a residential area consists of 10 major steps, which are summarized
More informationElectronic Document Review (EDR)
Electronic Document Review (EDR) Submittal Requirements Table of Contents Introduction... 3 Electronic Document Review Submittals:... 4 Plans... 4 Plat... 4 Forms... 4 Correspondence... 5 Plan Revisions...
More informationSANITARY SEWER SYSTEM ADMINISTRATIVE STANDARDS A.1 SANITARY SEWER SYSTEM PLAN SUBMITTAL PROCEDURES AND GENERAL REQUIREMENTS
SANITARY SEWER SYSTEM ADMINISTRATIVE STANDARDS A.1 SANITARY SEWER SYSTEM PLAN SUBMITTAL PROCEDURES AND GENERAL REQUIREMENTS All plans for sanitary sewer main extensions, improvements and modifications
More informationSECTION PROJECT MANAGEMENT AND COORDINATION
SECTION 013100 - PROJECT MANAGEMENT AND COORDINATION PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other
More informationThe GMFI Process. Design Intent Document Preparation. Enroll in GMFI Program. Image Consultation. You are here. Design Intent Document.
Enroll in GMFI Program Image Consultation Design Intent Document Preparation Preliminary Drawings Final Drawings Design Intent Document You are here. 1-2 Construction Documents Services performed by dealer
More informationFAST TRACK WORKSHOP OBJECTIVES
1 FAST TRACKING FAST TRACK WORKSHOP OBJECTIVES TO UNDERSTAND: 1. WHY ARE CRITICAL PATH ( FAST TRACK ) DESIGN SUBMITTAL PACKAGES ALLOWED 2. WHEN IS FAST TRACK ALLOWED 3. WHEN IS THE CONTRACTOR ALLOWED TO
More informationA. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:
SECTION 01 31 00 PROJECT MANAGEMENT AND COORDINATION PART 1 GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division
More informationSPECIAL PROVISION Description of Project, Scope of Contract and Sequence of Work
2004 Specifications CSJ 0110-04-166 SPECIAL PROVISION 000--363 Description of Project, Scope of Contract and Sequence of Work 1. General. The work to be performed on this project consists of furnishing,
More informationSubmittal Packages Detailed with Items and Reviewers
Submittal Packages Detailed with Items and Reviewers Tenochca Upgrades Project # 2351 San Diego State University 5500 Campanile Drive San Diego, CA 92182 Tel: 619-594-3740 Fax: 0054-096813-1 Tile Carpeting
More informationFTEV Repair Mezzanine Bldg Hurlburt Field, Florida SECTION DESIGN AFTER AWARD
SECTION 01 10 12 DESIGN AFTER AWARD 1. DESIGN RESPONSIBILITY The Contractor shall furnish and be responsible for a complete set of design documents as called for in specification section 01 10 10 DESIGN
More informationSECTION OPERATION AND MAINTENANCE DATA
SECTION 01787 OPERATION AND MAINTENANCE DATA PART 1 GENERAL 1.01 SUMMARY A. Compile product data and related information appropriate for OWNER's maintenance and operation of products furnished under Contract.
More informationSubmittal Exchange Design Team User Guide
Submittal Exchange Design Team User Guide Version 17 November 2017 Contents About This Guide... 9 Access/Permissions... 11 What is Submittal Exchange for Design?... 11 How Can I Get Submittal Exchange
More informationSCOPE: This procedure is applicable to construction projects and is an alternate method of submitting documentation for plan review and permitting.
Number: BD-020 Title: Electronic Plan Submittal and Review Effective Keywords: Permits, Plan Review, Plan Submittal Date: April 3, 2013 Revision Date: vember 4, 2015 Approved By: Thomas Hogarth Contact
More informationSTANDARD SPECIFICATION FOR CONTRACTOR'S DRAWING AND DATA TRANSMITTAL CONTRACTOR S DRAWING AND DATA TRANSMITTAL STANDARD SPECIFICATION FOR
THE ISRAEL ELECTRIC CORPORATION LTD. ENGINEERING PROJECTS GROUP SPECIFICATION No. 01-1E/S STANDARD SPECIFICATION FOR STANDARD SPECIFICATION FOR CONTRACTOR'S DRAWING AND DATA TRANSMITTAL CONTRACTOR S DRAWING
More informationPROJECT TITLE PROJECT NO: CONTRACT TITLE UNIVERSITY OF CALIFORNIA, DAVIS CITY, CALIFORNIA
SECTION 01 78 00 CLOSE-OUT SUBMITTALS PART 1 - GENERAL 1.1 GUARANTEES A. Compile and submit guarantees, bonds, and service and maintenance contracts specified in the individual B. Guarantees from Subcontractors
More informationBidders for the Oak Brook Park District Family Locker Room Renovation
BIDDING & CONTRACT REQUIREMENTS Document 00901 Addendum No. 1 Date: June 1, 2017 From: To: Wight Construction Services, Inc. 2500 Frontage Road Darien, IL 60561 Bidders for the Oak Brook Park District
More informationDesigner CM/Owner s Rep Prime Contractor SubContractor Supplier Manufacturer
Designer CM/Owner s Rep Prime Contractor SubContractor Supplier Manufacturer Construction Documents 1.1 to 1.6 Create Submittal Log 1.1 Construction Docs Focus of this process is to transmit submittal
More informationWATER MAIN ALONG ENTRANCE TO ENCINO PS / HWY 281 TO ENCINO TANK Solicitation Number: CO Job No.:
WATER MAIN ALONG ENTRANCE TO ENCINO PS / HWY 281 TO ENCINO TANK Solicitation Number: CO-00111 Job No.: 16-7003 To Respondent of Record: ADDENDUM 2 July 5, 2017 This addendum, applicable to work referenced
More informationBooster Pumping Station 115 Booster Pump Procurement
Madison Water Utility Tom Heikkinen General Manager 119 E. Olin Avenue Alan L. Larson PE, BCEE Principal Engineer Madison, Wisconsin 53713 Telephone: 608 266-4653 FAX: 608 266-4426 email: allarson@cityofmadison.com
More informationAIA Continuing Education
AIA Continuing Education Hall & Company is a Registered Provider with the American Institute of Architects Continuing Education Systems. Credit earned based on the completion of this program will be reported
More informationElectronic Plans Management Training. Submitting a Revision to Approved Plans (RTAP) Application & Uploading Drawings
Electronic Plans Management Training Submitting a Revision to Approved Plans (RTAP) Application & Uploading Drawings The Electronic Plan Management system (EPM) is an online tool designed to allow architects,
More informationKINGS COUNTY JAIL EXPANSION PHASE III COUNTY OF KINGS
SECTION 01 3100 - PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division 01 Specification Sections,
More informationLarge Scale CalArc Pavers for Sand-Set Pedestrian Use Installations
The following specification refers to the Stepstone, Inc. product known as: Large Scale CalArc Pavers for Sand-Set Pedestrian Use Installations Large Scale CalArc Pavers are part of the California Architectural
More informationNew Mexico Lottery Authority MY REWARDS PROGRAM DRAWING PROCEDURES v1.0
New Mexico Lottery Authority MY REWARDS PROGRAM DRAWING PROCEDURES v1.0 1.0 PURPOSE This document establishes the MY REWARDS Program (the Program ) Drawing Procedures utilized by the NEW MEXICO LOTTERY
More informationCity of Keizer Floodplain/Greenway Development Application
City of Keizer Floodplain/Greenway Development Application If there are any questions about this application, who should be contacted (Agent)? Name: Address: Daytime Phone Number(s): Fax: Email: 1. Applicant
More informationSECTION PHOTOGRAPHIC DOCUMENTATION
SECTION 01 32 33 PHOTOGRAPHIC DOCUMENTATION PART 1 - GENERAL 1.1 RELATED DOCUMENTS A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and other Division
More informationWTP FILTERS REHABILITATION (FILTERS 1, 2, 3, & 7) CITY OF CARTERSVILLE
WTP FILTERS REHABILITATION (FILTERS 1, 2, 3, & 7) ADDENDUM NO.1 ADDENDUM NO. 1 DATE: OCTOBER 16, 2018 To BID, CONTRACT, BONDS AND SPECIFICATIONS FOR CONSTRUCTING WATER TREATMENT PLANT FILTERS REHABILITATION
More informationENGINEERING DRAWINGS MANAGEMENT POLICY (IFC/AS BUILTS)
Approval Amendment Record Approval Date Version Description 15/10/2015 1 This policy takes precedence over L1-NAM-PRO-003 Infrastructure As Built Drawing Management due to business restructures. New Content
More informatione-submission Quick Reference Guide for Economic Operators
e-submission Quick Reference Guide for Economic Operators e-submission Quick Guide for Economic Operators Page 1 Welcome to e-submission. This quick reference guide contains: Introduction to e-submission
More informationPLA Planner Student Handbook
PLA Planner Student Handbook TABLE OF CONTENTS Student Quick Start Guide PLA Planner Overview...2 What is PLA Planner?...4 How do I access PLA Planner?...4 Getting to Know PLA Planner Home...5 Getting
More informationCity Plaza Energy Upgrades Timeline of Events Pella Window Cancellation
City Plaza Energy Upgrades Timeline of Events Pella Window Cancellation June 3, 2010 Pella asks what is needed for submittals. See Attachment #1. June 7, 2010 Pella (Matt Tison) confirms the receipt of
More informationThis section applies to the requirements for the performance of power system studies by both the Design Engineer and the Contractor.
Basis of Design This section applies to the requirements for the performance of power system studies by both the Design Engineer and the Contractor. Background Information A Short Circuit and Coordination
More informationMay 15, 2012 Hugh Anderson Legal Counsel to the Engineers Joint Contract Documents Committee
Shop Drawings: Contractual and Legal Issues May 15, 2012 Hugh Anderson Legal Counsel to the Engineers Joint Contract Documents Committee Shop Drawings Defined CSI definition: Drawings that illustrate a
More informationHarris County Capital Projects Electronic Submittal Guidelines for Consultants
Harris County Capital Projects Electronic Submittal Guidelines for Consultants This document sets forth the guidelines for electronic submittal for consultants as termed by Harris County Capital Projects.
More informationElectronic Plans Management Training. Upload Drawings
Electronic Plans Management Training Upload Drawings Upload Drawings The Electronic Plan Management system (EPM) is an online tool designed to allow architects, engineers, and designers the ability to
More informationSECTION STRUCTURAL STEEL. A. PART A and DIVISION 1 of PART B are hereby made a part of this SECTION.
SECTION 051200 PART 1 GENERAL 1.01 GENERAL REQUIREMENTS A. PART A and DIVISION 1 of PART B are hereby made a part of this SECTION. B. Examine all conditions as they exist at the project prior to submitting
More informationSection Project Closeout
Section 01700 - Project Closeout PART 1 GENERAL A. STIPULATIONS The section Special Requirements forms a part of this section by this reference thereto and shall have the same force and effect as if printed
More informationSpec Section: Concrete Mix Design psi - Review Form Concrete Mix Design psi Data Sheets GCAN
SUBMITTAL REVIEW Submittal: No. 013.00 Spec Section: 03 3000 2.11 Concrete Mix Design - 3500 psi - Review Form Reviewed By: Laura Landon, Comma-Q Architecture Date: May 10, 2012 Project: BPS Belgrade Elementary
More information00-General Drawings. Doc. no.: NA-00-STS002
Gæðaskjal (GSK) GSK-1773 Date of issue: 24.11.2016 Revision no.:2.0 Responsible: Einar Friðgeir Björnsson Editor: Rafn Magnús Jónsson 00-General Drawings Doc. no.: NA-00-STS002 This standard technical
More informationREMARKS: The A.F.F. dimension noted on the drawings to the bottom of the grid is 15 0, this dimension should be 16 0.
SUBMITTAL REVIEW SENT VIA: REGULAR MAIL OVERNIGHT FAX HAND DELIVERY DIGITAL DELIVERY OTHER: TO: Rodrigo Gorgazzi / CannonDesign Steve Benesh / CannonDesign Tim Donlon / FROM: Steven Cooper CC: David Barnett
More informationJanuary, 2014 Page 1 of 5
Part 1 General 1.1 General Instructions.1 These instructions add information to all articles of contracts with professionals..2 For each project, McGill University Facilities Operations and Development
More informationEngineering Drawing System
LPR 7320.1 Effective Date: February 2, 2010 Expiration Date: February 2, 2015 Langley Research Center Engineering Drawing System National Aeronautics and Space Administration Responsible Office: Systems
More informationSUBMITTAL REVIEW B Passenger Elevators Shop Drawings GCAN
SUBMITTAL REVIEW Submittal: No. 008 Spec Section: 14 2010 Passenger Elevators Reviewed By: Tripp Lewton, Comma-Q Architecture Date: May 17, 2012 Project: BPS Belgrade Elementary School Location: Belgrade,
More information