INFORMATION FOR RESPONDENTS

Transcription

1 PURCHSING SECTION venue, Surrey BC V3T V8 Tel: DDENDUM #2 REQUEST FOR EXPRESSIONS OF INTEREST ND STTEMENTS OF QULIFICTIONS (RFEOI/SOQ ) NO.: TITLE: SUPPLY, DELIVERY ND INSTLLTION OF REFRIGERTION PLNT ND REN FLOOR PCKGE DDENDUM ISSUE DTE: May 8, 207 CLOSING DTE: prefer to receive Submissions on or before: May 6, 207 INFORMTION FOR RESPONDENTS This ddendum is issued to provide additional information to the RFEOI/SOQ for the above named project, to the extent referenced and shall become a part thereof. No consideration will be allowed for extras due to the Respondent not being familiar with this ddendum. This ddendum No. 2 contains 42 pages in total. RFEOI/SOQ TITLE CHNGE The title of RFEOI/SOQ # for Supply, Delivery and Installation of Refrigeration Plant and rena Floor Package is hereby changed to Pre-qualification for rena Refrigeration Plant System Contractor. ll references to Supply, Delivery and Installation of Refrigeration Plant and rena Floor Package shall now read Pre-qualification for rena Refrigeration Plant System Contractor. CLRIFICTIONS ND/OR MODIFICTIONS ) Schedule Scope of Services and Schedule B Form of Submission are hereby deleted and substituted with the attached Schedule and Schedule B. END OF DDENDUM #2 ll ddenda will become part of the RFEOI/SOQ Documents.

2 SCHEDULE SCOPE OF SERVICES. PURPOSE The City of Surrey (the City ) invites request for expressions of interest and statements of qualifications for specialized contractors for the supply, delivery, installation and commissioning of arena refrigeration plant system and associated works for the following projects: North Surrey Sports & Ice Complex located at venue in Surrey, BC. Cloverdale Sport & Ice Complex located at Cloverdale Fairgrounds (lots 7770, 786, and venue; 7763 and venue) Surrey, British Columbia. 2. BCKGROUND The City of Surrey: The City of Surrey is an energetic and dynamic city known for business and investment opportunities supported in part by its progressive and forward thinking economic vision. Surrey is a city within the greater Vancouver Census Metropolitan rea just over 40 minutes from downtown Vancouver and 30 minutes from the Vancouver International irport. The City's population, estimated at 502,000 people, experienced a growth rate of 3%+ from 200 to 2006 and is centered in a region that has a population in excess of 2.2 million people. The City is the second largest city in BC. Based on its high growth rate, the City is expected to surpass Vancouver to become the largest city in the Province of BC in terms of population in the next 20 years ±. Surrey's City Centre has been identified as Metro Vancouver's "2nd metropolitan core" and the downtown for the Fraser Valley. The City is traversed by five major highways and four railways, has deep-sea docking facilities and is located near an international airport. Two Canada/United States border crossings are located on the southerly boundary of Surrey. North Surrey Sports & Ice Complex: The North Surrey Sports & Ice Complex will be a new facility providing three (3) NHL sized arena sheet spaces for the use by ice and dry floor sports, lessons and recreation. The 2,500 sq.m. building will include change rooms, officials rooms, spectator seating, fitness, yoga room, spin bike room and supporting facilities. Front of house facilities include entry lobby, coffee place with lounge, skate rental shop and lace up benches/cubbies. dditional community spaces include multi-purpose rooms and meeting rooms. rchitectural Drawings are included in ttachment #. Design-Builder Lark Group has been retained by the City as a Design-Builder. Refrigeration / Ice Plant Bradley Refrigeration Consultants Ltd. RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page of 8

3 Project Manager Turnbull Construction Project Managers Ltd. has been retained by the City as the Project Manager. Cloverdale Sport & Ice Complex: The Cloverdale Sport & Ice Complex will be a new facility providing two (2) NHL sized arena sheet spaces for the use by ice and dry floor sports, lessons and recreation. The 8,500 sq.m. building will include change rooms, officials rooms, seating for 200 spectators per sheet, and supporting facilities. Front of house facilities include entry lobby, servery / vending lounge, skate rental shop and lace up benches/cubbies. dditional community spaces include 2 large multi-purpose rooms and 2 meeting rooms. Site development includes a new extension to 77B Street south of 64 venue, improvements to the Millennium amphitheatre Back-of-House, relocation of a Cloverdale Fairgrounds operations building, upgrades and improvements to 62 venue and the existing parking lot opposite the griplex building as well as new parking for approximately 240 spaces to serve the new arena. Schematic Design Drawings are included in ttachment #2. rchitect Taylor Kurtz rchitecture + Design Inc. in association with Rounthwaite Dick and Hadley rchitects Inc. have been retained by the City as the prime consultant. Refrigeration / Ice Plant Bradley Refrigeration Consultants Ltd. Project Manager City staff has been appointed to be the Project Manager representing the City. 3. CURRENT PROJECT STTUS North Surrey Sports & Ice Complex: Schematic design has been completed and DP application submitted to the City. Design development phase is ongoing. Cloverdale Sport & Ice Complex: Schematic design has been completed. Design development phase is ongoing. Design team is currently coordinating with the user group, once finalized design will move onto for full working drawings phase. The City is in the process of hiring a construction manager for integration of its service into the remainder design phase and to ensure design and budget alignment. 4. PROJECT OBJECTIVES ND SCOPE The City intends to engage a qualified contractor for the supply, delivery and installation of refrigeration plant and associated works for arena floor. This project consists of the ammonia refrigeration plant and arena floor materials. ll works to be completed to accepted best practices for the arena floor assembly. RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 2 of 8

4 The work includes the supply, installation, start up, commissioning and warranty of a new ammonia refrigeration plant and arena floors for the NHL size rinks for the North Surrey Sports & Ice Centre and Cloverdale Sport & Ice Complex. The work is to be complete system with piping and controls as per drawings and specifications. The refrigeration plant is to be capable of making ice in three (3) days in the month of ugust on one sheet when the one sheet of ice is installed and the other sheets are being flooded. The concrete slabs will be done by the arena floor contractor. ll works to be completed to accepted best practices for high quality and sustainable refrigeration practices. 5. PREFERRED EXPERIENCE, CPBILITY, CPCITY ND RESOURCES The City prefers that the Respondent is an ammonia refrigeration contractor that has experience, capability and resources with projects consisting of the following:. ll material, construction, installation and work shall be carried out in compliance with the CN/CS B Mechanical Refrigeration Code, NSI B3., B3.5, the Canadian Electric Code CS C22., CS Standard Z for safeguarding of machinery, latest revisions and updates in effect at the time of installation. Comply with all local building bylaws, Provincial, Federal and WCB codes, policies, rules and ordinances, IIR and SHRE Standards..2 Pressure vessels will comply with CS Standard B.5 and SME codes. Vessels, valves, heat exchangers, condensers and other pressure containing components will be approved for use in the Province of British Columbia. ll pressure containing components shall be listed individually or as part of refrigeration equipment by an approved nationally recognised testing laboratory. ll pressure-retaining components must be constructed to a design that is registered as a pressure vessel, fitting or piping system..3 Only experienced tradesmen qualified under Provincial regulations will be employed on this project. The refrigeration contractor must have a minimum of three (3) qualified journeyman with ammonia refrigeration experience on staff to bid on this work. Names and trades qualification certificates must be submitted as part of the Contractor s qualifications..4 Contractors bidding this work will be experienced in the installation of refrigeration equipment in plants of this size. The refrigeration contractor must have installed three (3) new ammonia arena refrigeration plants and arena floors with plate and frame chillers in the last five (5) years. Records of these installations should be submitted as part of their qualifications..5 full time supervisor suitable to the City and the Engineer will be employed to supervise the complete project. This supervisor shall cooperate and co-ordinate with the City and/or the Engineer to locate equipment, anchors and supports. RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 3 of 8

5 6. PROJECT TIMELINE The City has identified the following anticipated key milestone dates: North Surrey Sports & Ice Complex: Task Description nticipated Date Design February September 207 Procurement N Construction July 207 Occupancy Summer 209 Cloverdale Sport & Ice Complex: Task Description nticipated Date Design Development February Summer 207 Procurement Summer/Fall 207 Construction Fall/Winter 207 Occupancy Spring 209 The above dates are anticipated and as such are subject to change. 7. HELTH & SFETY The Contractor will undertake all health and safety matters in accordance with applicable legislation and good industry standards. The Contractor will undertake all health and safety matters in accordance with company occupational health and safety program and the site-specific safety program that will be developed based on the safety, environmental, and operational risks associated with the proposed construction project. The Contractor will promote, assist at, and demonstrate a positive safety attitude at the Place of the Work. 8. WORKPLCE HZRDOUS MTERILS INFORMTION SYSTEM The Contractor will ensure that all materials subject to Workplace Hazardous Materials Information System (WHMIS) requirements are properly identified, labeled, used, and stored in accordance with the general requirements of the Hazardous Products ct and the Hazardous Materials Information Review ct, as amended from time to time, and the specific requirements of the Material Safety Data Sheet (MSDS) for the specific product. The Contractor will ensure that all hazardous materials are properly labelled and have the accompanying MSDS prior to arrival and use at the Place of the Work. Copies of MSDS will be made available for reference and review by the City. RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 4 of 8

6 Type of Pre-Qualification: SCHEDULE B FORM OF SUBMISSION RESPONDENT S REQUEST FOR EXPRESSIONS OF INTEREST ND STTEMENTS OF QULIFICTIONS This Request For Expressions of Interest and Statements of Qualifications (RFEOI/SOQQ) will enable the City of Surrey (the City ) to determine your relevant experience, capacity, resources, and financial capability for eligibility to submit a Request For Proposal for contractor work packages for the North Surrey Sports & Ice Centre and Cloverdale Sport & Ice Complex. Materially incomplete RFEOI/SOQ submissions may be deemed to fail the qualification process. Respondents may supplement information requested with additional sheets if required. ll information provided should be relevant to the prequalification. Project Description: Project Title: Pre-qualification for rena Refrigeration Plant System Contractor Project Reference No.: The City invites experienced and qualified ammonia refrigeration contractors for the supply, installation, start up, commissioning and warranty of a new ammonia refrigeration plant and arena floors for NHL size rinks for the North Surrey Sports & Ice Centre and Cloverdale Sport & Ice Complex. Submitted To: City Representative: ddress: Richard D. Oppelt, Purchasing Manager Surrey City Hall Finance & Technology Department Purchasing Section Reception Counter, 5 th Floor West venue, Surrey, B.C., Canada, V3T V8 Telephone: Fax: for PDF Files: purchasing@surrey.ca RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 5 of 8

7 SECTION. GENERL INFORMTION This document is intended to provide information on the capacity, skill, and experience of the Respondent. Respondents may supplement information requested with additional sheets if required.. 2. Full Legal Name of Firm Business ddress 3. Phone No.: Fax No.: 4. ddress: Website ddress: 5. Contact for prequalification inquiries (full name, position and address): 6. Contact for general inquiries (full name, position and address): 7. Membership of industry associations (please list): SECTION B. COMPNY PROFILE 8. How many years has your organization been in business as a contractor? 9. How many years has your organization been in business under its present business name? 0. Form of Business Organization Corporation Partnership Sole Proprietorship. If Corporation/Partnership, year incorporated/established: 2. If the Respondent is a company, the company name indicated above is registered with the Registrar of Companies in the Province of British Columbia, Canada, Incorporation Number. SECTION C. FINNCIL CPCITY Insurance Reference: 3. Name of Insurance Company: 4. ddress: 5. Contact Person: RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 6 of 8

8 6. Telephone/Fax Numbers: Phone: Fax: 7. re you able to provide General Liability Insurance, on an occurrence basis, in the amount of not less than $5,000,000 (CD) with an insurer licensed in British Columbia for bodily injury, (including death) and damage to property including loss of use thereof? Yes No 8. re you able to provide utomobile Liability Insurance for a limit of not less than $3,000,000 (CD) for all owned, leased or rented licensed vehicles used in the performance of Work and shall include third party liability? Yes No 9. re you able to provide ll Risk Course of Construction (Builder s Risk) Insurance for the value of the work performed and the full value of products specified by the City, if any, for incorporation into contract works? Yes No 20. re you able to provide Contractor's Equipment Insurance covering at least the actual cash value of owned or leased construction machinery and equipment used in the performance of the Work and shall include a waiver of rights of subrogation against the Owner and the Consultant? Yes No 2. Do you carry Professional Errors and Omissions Insurance? Yes No If Yes, provide the following details: (i) mount of coverage: (a) Per Occurrence / Claim: (b) ggregate: (ii) Detail specific exclusions (if any): Comment: (iii) Detail whether there is a limit on the number of claims per annum: Comment: Note: Refer also to the City s sample insurance certificate form available on the City's web site at (search "Insurance Certificates") titled City of Surrey Certificate of Insurance Standard Form. Bonding Reference: 22. Name of Bonding Company: 23. ddress: 24. Contact Person: 25. Telephone/Fax Numbers: Phone: Fax: RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 7 of 8

9 26. of Surety Reference: 27. Can your firm provide a Bid Bond? Yes No BONDING LIMIT ($) 28. Can your firm provide a Performance Bond? Yes No BONDING LIMIT ($) 29. Can your firm provide a Labour & Material Payment Bond? Yes No BONDING LIMIT ($) 30. Current Bonding In Effect: $ nnual Project Volumes: 3. pproximate annual value of construction projects completed in each of the last five years: Year Value (Labour, Equipment and Materials) $ $ $ $ $ 32. Indicate the dollar volume of work for which you presently have contracts, but have not started or completed to date: $. SECTION D. WORK EXPERIENCE PROFILE 33. Respondents should provide details, in order of date, of relevant arena refrigeration plant system projects completed in the past five years Schedule B ppendix (data sheet). 34. Respondents should provide details, in order of date, of relevant arena refrigeration plant system projects underway as of Submission Date Schedule B - ppendix B (data sheet). 35. Management and Personnel: Qualifications and relevant experience of senior management and key technical staff: (a) brief resume identifying each individual s qualifications and relevant professional experience and the number of years they have worked for the Respondent; (b) specific projects worked on; and (c) details of the training that will be provided to field personnel. 36. Subcontractors: Respondents should provide the following information on the background and experience of all sub-contractors (including consultants and material suppliers) proposed to undertake a portion of the Services (use the spaces provided and/or attach additional pages, if necessary): DESCRIPTION OF SERVICES SUB- CONTRCTORS NME YERS OF WORKING WITH RESPONDENT TELEPHONE NUMBER ND EMIL RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 8 of 8

10 Do you evaluate the ability of subcontractors to comply with applicable Health, Safety and Environment requirements as part of the selection process? Yes No Do you include subcontractors in: udits? Yes No Health, Safety and Environment Meetings? Yes No Health, Safety and Environment Orientation? Yes No Inspections? Yes No Do your subcontractors have a written Health, Safety and Environment Management Program or System? Yes No Do you use Health, Safety and Environment performance criteria in the selection of subcontractors? Yes No 37. Respondents should provide details of your approach to selecting subcontractors, suppliers addressing in particular: The subcontractors and suppliers you have successfully used on previous construction and related works projects that could be used in the future on various procurement opportunities that may arise within the time period of this RFEOI/SOQ; and Your approach to achieve competitive pricing and excellent quality: Comments: 38. Management of consultants, subcontractors and material supplier(s). Respondents should provide details of the approach to the management of its consultants, subcontractors and material suppliers: Comments: 39. Respondent should describe the availability of staff to work on this project including your capacity to undertake project, in terms of maximum available crew size (Estimated): Comments: SECTION E. TECHNICL CPCITY 40. Workers Compensation Board Information: Workers Compensation Registration Number: Letter of Good Standing attached: Yes No RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 9 of 8

11 4. Equipment and Materials: Do you maintain a list of the major equipment (e.g., cranes, forklifts) your company has available for work at this site, and the method of establishing the competencies to operate this equipment? Yes No. Respondent should provide a representative list of major equipment and size. Do you conduct inspections on operating equipment (e.g., cranes, forklifts) in compliance with the regulatory requirements? Yes No Do you have a system for establishing the applicable Health, Safety and Environmental specifications for the acquisition of materials and equipment? Yes No Do you maintain operating equipment in compliance with the manufacturer s and any local legislative requirements? Yes No Do you maintain the applicable inspection and maintenance certification records for operating equipment? Yes No 42. Quality Control Program: Respondents should provide a description of their quality control program; how it works, personnel who provide it, standards by which the effectiveness of the program can be measured, record of results on previous projects, etc. Comments: 43. Health and Safety: Utilization of Occupational Health and Safety (OH&S) Respondents should provide evidence of a current program in place, a sample or example OH&S program with a general construction safety program for all workers. Do you have specific Health and Safety Training Program for supervisors? Yes No Have your employees received the required Health and Safety training and retraining? Yes No Corporate OH&S policy attached (please tick to confirm). Has your company received any awards for health and safety performance achievement? Yes No If Yes, please list. 44. Utilization of Waste Management & Reduction Policy and Plan: Respondents should provide evidence of a system in place, a sample or example Waste Management & Reduction Plan. Corporate Waste Management & Reduction policy attached (please tick to confirm). Corporate Waste Management & Reduction Plan attached (please tick to confirm). RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 0 of 8

12 45. Utilization of Traffic Management: Respondents should provide evidence of a system in place, a sample or example traffic management policy and appropriate procedures. Corporate Traffic Management policy attached (please tick to confirm). Corporate Traffic Management Plan attached (please tick to confirm). 46. Contracts: (a) Has your firm or any predecessor firm defaulted on a contract or had work terminated for nonperformance within the last five (5) years? Yes No If Yes, Respondent should briefly describe the project, owner, date and the circumstances/reason(s): Comments: (b) Respondent should identify projects where there were any outstanding deficiencies. List any contractor charge backs or liquidated damages assessed for failure to complete on time: Comments: (c) Respondent should briefly describe any work that was rejected by an owner or that was not paid for or had to be removed and replaced. Comments: (d) Respondent should briefly describe any work that conditionally accepted by an owner but with a contractor charge back or partial payment: Comments: 47. Scheduling: (a) Does your firm use the critical path method? Yes No (b) Does your firm use computerized scheduling? Yes No (c) If so, what software is used? Comments: RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page of 8

13 48. Respondent should list the categories of work that your organization normally performs with its own forces. Comments: 49. Customer Service: Respondents should briefly describe your company s standards and associated process with respect to response time regarding resolution of service issues. This includes but is not limited to technical support, warranty claims, non-conformance, and order placement issues. Comments: 50. Technical Support Service: Respondents should provide an overview of technical support services available from your company, such as product assessment, identification of specification changes, and troubleshooting problems. Comments: 5. What other information is not requested here but which you think the City should consider in evaluating your company? Comments: I/We confirm that this Submission is accurate and true to best of my/our knowledge. This Submission is submitted this day of, 20_. I/We have the authority to bind the Respondent. (Name of Respondent ) (Signature of uthorized Signatory) (Print Name and Position of uthorized Signatory) (Name of Respondent) (Signature of uthorized Signatory) (Print Name and Position of uthorized Signatory) RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 2 of 8

14 PPENDIX RELEVNT REN REFRIGERTION PLNT SYSTEM PROJECTS (in order of date) COMPLETED IN THE PST FIVE YERS. ttach additional pages, if necessary as follows (as applicable): Ref. #. Project Title and Date: Project Description: Location of Project: Original Contract Value: Project Manager: Subcontract Value: Date: $ Final Contract Value: $ Superintendent: $ Original Planned Completion Date: ctual Completion Date: Name of Contract Owner: Refer To: Telephone/Fax Numbers: Phone: Fax: Name of Consultant: Refer To: Telephone/Fax Numbers: Phone: Fax: Ref. #2. Project Title and Date: Project Description: Location of Project: Original Contract Value: Project Manager: Subcontract Value: Date: $ Final Contract Value: $ Superintendent: $ Original Planned Completion Date: ctual Completion Date: Name of Contract Owner: Refer To: Telephone/Fax Numbers: Phone: Fax: Name of Consultant: Refer To: Telephone/Fax Numbers: Phone: Fax: Ref. #3. Project Title and Date: Project Description: Location of Project: Original Contract Value: Project Manager: Subcontract Value: Date: $ Final Contract Value: $ Superintendent: $ Original Planned Completion Date: ctual Completion Date: Name of Contract Owner: Refer To: Telephone/Fax Numbers: Phone: Fax: Name of Consultant: Refer To: Telephone/Fax Numbers: Phone: Fax: RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 3 of 8

15 PPENDIX B RELEVNT REN REFRIGERTION PLNT SYSTEM PROJECTS (in order of date) UNDERWY S OF SUBMISSION DTE (in order of date). ttach additional pages, if necessary as follows (as applicable): Ref. #. Project Title and Date: Project Description: Location of Project: Original Contract Value ($): Project Manager: Scheduled Completion Date: Name of Contract Owner: Refer To: Date: Subcontract Value ($): Superintendent: Percent (%) Completed: Telephone/Fax Numbers: Phone: Fax: of Project Reference: Name of Consultant: Refer To: Telephone/Fax Numbers: Phone: Fax: Telephone/Fax Numbers: Phone: Fax: Ref. #2. Project Title and Date: Project Description: Location of Project: Contract Value ($): Project Manager: Scheduled Completion Date: Name of Contract Owner: Refer To: Date: Subcontract Value ($): Superintendent: Percent (%) Completed: Telephone/Fax Numbers: Phone: Fax: of Project Reference: Name of Consultant: Refer To: Telephone/Fax Numbers: Phone: Fax: Ref. #3. Project Title and Date: Project Description: Location of Project: Contract Value ($): Project Manager: Scheduled Completion Date: Name of Contract Owner: Refer To: Date: Subcontract Value ($): Superintendent: Percent (%) Completed: Telephone/Fax Numbers: Phone: Fax: Name of Consultant: Refer To: RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 4 of 8

16 TTCHMENT # NORTH SURREY SPORTS & ICE COMPLEX RCHITECTURL DRWINGS RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 5 of 8

17 684 West 2nd venue Vancouver BC V6J H4 CND Notes Revisions/Issues: Project Title: ISSUED FOR DP NORTH SURREY SPORTS & ICE CENTRE #26 STREET, SURREY, BC Client: THE CITY OF SURREY Sheet Title: COVER PGE This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: uthor Project North: Reviewed by: Checker Date: 03/28/7 Plot Date: 4//207 7:4:33 PM Graphic Scale: Scale: Project No.: 267 Drawing No.: -000

18 OUTSIDE WE TYPICL EXTERIOR CURTIN WLL - GLZING - THERMLLY BROKEN 4-SSG PRE FINISHED LUMINIUM CURTIN WLL SYSTEM - 'LOW - E' TEMPERED DOUBLE GLZING WI4 TYPICL INTERIOR WLL - SHFT WLL mm CH O.C mm TYPE X GWB - 2X6mm TYPE X GWB OUTSIDE WE2 TYPICL EXTERIOR WINDOW WLL - GLZING - THERMLLY BROKEN STICK FRMED PRE FINISHED LUMINIUM WINDOW WLL SYSTEM - 'LOW - E' TEMPERED DOUBLE GLZING WF TYPICL INTERIOR WLL - FURRING - 52mm METL O.C. W/ MINERL FIBRE BTT COUSTIC INSULTION - 6mm GWB 684 West 2nd venue Vancouver BC V6J H4 CND Notes OUTSIDE WE3 TYPICL EXTERIOR WLL - METL INSULTED PNEL WF TYPICL INTERIOR WLL - FURRING - 52mm METL O.C. W/ MINERL FIBRE BTT COUSTIC INSULTION - 6mm GWB OUTSIDE - 75mm PRE - ENGINEERED INSULTED WLL SYSTEM - HORIZONTL METL GIRT - 52mm METL 400mm O.C. - 6mm IMPCT RESISTNT GWB WF3 TYPICL INTERIOR WLL - FURRING - 22mm FURRING CHNNEL - 6mm GWB WE4 TYPICL EXTERIOR WLL - METL INSULTED PNEL - 75mm PRE - ENGINEERED INSULTED WLL SYSTEM - HORIZONTL METL GIRT - 90mm CMU - FINISH PER DRWINGS WF4 TYPICL INTERIOR WLL - FURRING - 2.7mm RESILIENT CHNNEL - 6mm GWB OUTSIDE WE5 R VLUE =.24 TYPICL EXTERIOR WLL - POLYCRBONTE PNEL - 60mm POLYCRBONTE PNEL SYSTEM WG TYPICL INTERIOR GLSS - SINGLE - LUMINIUM MULLIONS - CLER SINGLE GLZED UNIT - SPCING PER WINDOW SCHEDULE WI TYPICL INTERIOR WLL - CMU (FILLED) - 90mm CONCRETE MSONRY UNIT - PINT FINISH ISSUED FOR DP WI2a TYPICL INTERIOR WLL - 92mm METL FRME - 6mm GWB - 92mm METL O.C. - 6mm GWB Revisions/Issues: Project Title: NORTH SURREY SPORTS & ICE CENTRE #26 STREET, SURREY, BC Client: THE CITY OF SURREY WI2b WI3a TYPICL INTERIOR WLL - 92mm METL FRME - 6mm GWB - 92mm METL O.C. W/ MINERL FIBRE BTT COUSTIC INSULTION - 6mm GWB TYPICL INTERIOR WLL - 52mm METL FRME - 6mm GWB - 52mm METL O.C. - 6mm GWB Sheet Title: This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: Reviewed by: Checker Date: 0/30/7 Plot Date: 4//207 7:4:43 PM SSEMBLIES uthor Project North: Graphic Scale: WI3b STC = 50 TYPICL INTERIOR WLL - FURRING - 52mm METL O.C. W/ MINERL FIBRE BTT COUSTIC INSULTION - 6mm GWB Scale: : 0 Project No.: 267 Drawing No.: -00

19 CEILING SPCE C TYPICL INTERIOR CEILING - SUSPENDED GWB - SUSPENDED METL FRMING - 9mm GWB CEILING SPCE C2 STC = VRIES TYPICL INTERIOR CEILING - COUSTIC CEILING - RESILIENT CHNNEL - 2 X 6mm TYPE X GWB 684 West 2nd venue Vancouver BC V6J H4 CND CEILING SPCE OUTSIDE Notes OUTSIDE C3 F TYPICL INTERIOR CEILING - T-BR - T - BR CONCRETE SUSPENDED SLB - FLOOR FINISH (REFER TO SPECIFICTION ND FINISH SCHEDULE) - 200mm SUSPENDED SLBS ON GRDE BEMS ND PILES W/ RDON GS BRRIER ND PSSIVE EXTRCTION SYSTEM R3 COUSTIC INSULTION TOP SIDE OF FLUTE PERFORTED STEEL DECKING COUSTI DECK OR SIMILR CURVED ROOF - TYPICL - TPO ROOFING MEMBRNE - 2.7mm SHETHING - 2X RIGID INSULTION (STGGERED, R20 MIN. ) - SELF DHERED IR / VPOUR BRREIER -STEEL DECKING, DEEP DECK OR COMSLB 8 OR 0" PER STRUCTUL (COUSTIC INSULTION IN PERFORTED STEEL DECKING) - GLULM BEMS PER STRUCTURL OUTSIDE F2 CONCRETE ICE RINK - 40mm ICE SURFCE - 30mm CONCRETE SLB W/ 25mm Ø COOLING 00mm O.C. - PIPE CHIRS. MESH & REBR - 6ml POLY VPOUR BRRIER (JOINTS LPPED ND SELED) - 2X 50mm RIGID INSULTION (2 LYERS DOW SM. HIGH DENSITY INSULTION - SHIPLP JOINTS, STGGERED INSTLL'N) - 6ml POLY VPOUR BRRIER (JOINTS LPPED ND SELED) - 305mm FINE WSHED SND (NO SILT OR ROCKS) C/W 25mm Ø HETING 305mm O.C. FILL - 200mm SUSPENDED SLBS ON GRDE BEMS ND PILES W/ RDON GS BRRIER ND PSSIVE EXTRCTION SYSTEM OUTSIDE R2 FLT ROOF - TYPICL - TPO ROOFING MEMBRNE - 2.7mm SHETHING - 2X RIGID INSULTION (STGGERED, R20 MIN. ) 2.7mm PROTECTION BORD - VPOUR BRRIER - METL DECK PER STRUCTURL - STEEL TRUSS PER STRUCTURL F3 CONCRETE SUSPENDED SLB - FLOOR FINISH (REFER TO SPECIFICTION ND FINISH SCHEDULE) - CONCRETE SLB PER STRUCTURL (REFER TO STRUCTURL FOR DEPTH) ISSUED FOR DP Revisions/Issues: Project Title: NORTH SURREY SPORTS & ICE CENTRE #26 STREET, SURREY, BC Client: THE CITY OF SURREY Sheet Title: SSEMBLIES CONTINUED This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: uthor Project North: Reviewed by: Checker Date: 0/30/7 Plot Date: 4//207 7:4:52 PM Graphic Scale: Scale: : 0 Project No.: 267 Drawing No.: -002

20 684 West 2nd venue Vancouver BC V6J H4 CND a 3 2a 2 a Notes T.O. GLULM (U) 6400 METL FCI PINTED TO MTCH KINGSPN METL PNEL IN LIGHT GREY T.O. GLULM (L) 3200 STOREFRONT MULLION PINTED TO MTCH KINGSPN METL PNEL IN LIGHT GREY CLER GLSS TPO ROOFING MEMBRNE METL INSULTED PNEL LUMINUM CUT LETTERS MOUNTED TO EXTERIOR WLL STND OFF TO BE 25MM Level Level Revisions/Issues: Project Title: ISSUED FOR DP NORTH SURREY SPORTS & ICE CENTRE #26 STREET, SURREY, BC Client: THE CITY OF SURREY Sheet Title: SIGNGE Level METL DOOR PINTED TO MTCH KINGSPN METL PNEL IN DRK GREY 0 This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: uthor Reviewed by: Checker Project North: Signage - North Elevation : 50 Date: 04/07/7 Plot Date: 4//207 7:42:42 PM Graphic Scale: Scale: : 50 Project No.: 267 Drawing No.: -003

21 B B B B B B B B B B B B B B B B B B B B B BBBB B B B B BBB B B 684 West 2nd venue Vancouver BC V6J H4 CND STREET PROJECT STTISTICS ZONING: STNDRDS: IL (LIGHT IMPCT INDUSTRIL ZONE) BCBC 202 (BRITISH COLUMBI BUILDING CODE) & SURREY ZONING BYLW (2000) Notes MJOR OCCUPNCY: 3 (RENS & ICE RINKS) SCOTT ROD 26 STREET 0 VE 28 STREET 0 VE CONSTRUCTION: NON COMBUSTBLE W/ HEVY TIMBER ROOF STRUCTURE FIRE PROTECTION: BUILDING IS TO BE SPRINKLERED TO NFP 3 PER BCBC 202 SITE RE: m 2 BUILDING HEIGHT: BUILDING SETBCKS: FRONT: 7.5m BCK: 7.5m SIDE: 7.5m FSR: m MX BUILDING HEIGHT 8m OR 60' PER SENTNCE 48.G. NOT TO EXCEED.00 OF THE SITE PROPOSED: 2486/47085m 2 =.265 LOT COVERGE: MXIMUM 60% PROPOSED: 0637/47085m 2 = 23% 24 STREET 09 VENUE 25 STREET NSSIC 28 STREET 29 STREET 09 VE 29 STREET CR PRKING BYLW: REQUIRED PRKING: NUMBER OF REQUIRED STLLS: PRT 5 TBLE C. RECRETION FCILITY/ICE RINK 5.0 PRKING SPCES PER 00m 2 OF FLOOR RE 2.5 PRKING SPCES PER 00m 2 OF FLOOR RE USED S SKTING RINK RECRETION RE 2400m 2 /00m 2 * 5 =20 STLLS SKTING RE 3 = 4546m 2 /00m 2 * 2.5 = 4 STLLS REC SKTING RINK LEVEL SERV. LEVEL 2 REC SKTING RINK TOTL = 234 STLLS PRKING FOR PERSONS WITH DISBILITIES: REQUIRES 2 STLLS BC HYDRO SWM WY ISSUED FOR DP Revisions/Issues: OLD YLE ROD 08 VE NUMBER OF STLLS PROVIDED: PRKING STLL TYPE TYP. 224 FIRE TRUCK ELEC. 2 DROP OFF 2 Project Title: NORTH SURREY SPORTS & ICE CENTRE Client: #26 STREET, SURREY, BC THE CITY OF SURREY 24 STREET 25 STREET 25B STREET 27 STREET 27 STREET 28 STREET OLD YLE ROD 07 VE 06 VE BICYCLE PRKING NUMBER OF SPCES REQUIRED: NUMBER OF SPCES PROVIDED: CC. 4 TOTL PRKING STLLS: 243 N/ 3 Sheet Title: This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: Reviewed by: Checker Date: CONTEXT PLN & DT 04/07/7 Plot Date: 4//207 7:43:25 PM Graphic Scale: uthor Project North: Location Plan : 2000 Scale: Project No.: s indicated 267 Drawing No.: -00

22 M M 3.62 M M SLB ELEVTION =5.0m 3.52 M M M M M M 4.90 H 0 VENUE 44 9' 53" m SPHLT CURB 28 STREET CC. CC. CC. CC. ELEC. ELEC. DROP OFFDROP OFF DROP OFF DROP OFFDROP OFF DROP OFF DROP OFF DROP OFFDROP OFF FIRE TRUCK DROP OFF DROP OFF DROP OFF m 90 00' 00" 8.84 m 0 00' 00" 8.84 m 0 00' 00" 2600 TYP ' 00" m EXTENT OF WORK EXISTING POND / STORM WTER RETENTION RE 7500 SRW PLN BCP20073 ZONE SRW PLN BCP20073 ZONE 2 SRW PLN BCP20073 ZONE SLB ELEVTION = 5.0m EXTENT OF WORK FUTURE SIGN LOCTION 7000 COOLING TOWER CREEK 0m SET BCK FROM TOP OF CREEK BNK BC HYDRO LINE TO PMT PMT GRBGE SYMBOLS EXISTING TREE PROPOSED TREE PROPERTY LINE PROPOSED SET BCK RIGHT OF WY EXTENT OF WORK Notes Revisions/Issues: Project Title: Client: Sheet Title: This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: Date: Scale: 684 West 2nd venue Vancouver BC V6J H4 CND Reviewed by: Plot Date: 4//207 7:44:42 PM Graphic Scale: Project No.: ISSUED FOR DP NORTH SURREY SPORTS & ICE CENTRE 0/25/7 s indicated 267 #26 STREET, SURREY, BC THE CITY OF SURREY uthor Checker Site Plan Project North: Drawing No.: PROPOSED PROPERTY LINE Site : 500

23 G F E D C B STFF MULTIPURPOSE m² ELEC. OFFICE OFFICE OFFICE SECURITY/ SFE ROOM VESTIBULE 684 West 2nd venue Vancouver BC V6J H4 CND a 2 2a RMP FEMLE W.C. MLE W.C. STFF ROOM 3.63 m² STFF CHNGE RM 250 CUBBIES COMMS JN / SKTE SHOP STORGE 3.0 m² STORGE 9.22 m² SKTERS LOBBY m² RECEPTION m² ENTRNCE LOBBY m² VENDING CFE OFFICE STORGE STORGE MEETING ROOM m² FEMLE W.C. W.C. MLE W.C. W.C. JN FOREMN OFFICIL OFFICIL CHNGE ROOM CHNGE ROOM 2 CHNGE ROOM 3 CHNGE ROOM 4 CHNGE ROOM 5 Notes 3 3a 4 4a 5 5a 6 6a 7 7a 8 8a 9 9a SETS 25 SETS 25 SETS 25 SETS 25 SETS 25 SETS RMP 25 SETS 25 SETS FUTURE SETING FUTURE SETING PENLTY SCORE PENLTY FLEX SETING FLEX SETING 450 STORGE 93.2 m² RINK m² WORKSHOP m² WC ICE RESURFCING UNIT RE m² ICE MELT CHNGE ROOM CHNGE ROOM 2 CHNGE ROOM 3 CHNGE ROOM 4 CHNGE ROOM 5 ELEV m² OFFICIL OFFICIL JN. Room OFFICIL OFFICIL STORGE OFFICE CHNGE ROOM 0 CHNGE ROOM 9 CHNGE ROOM 8 CHNGE ROOM 7 CHNGE ROOM 6 PHYSIOTHERPY CHNGE STORGE ROOM m² RINK m² ICE RESURFCING UNIT RE m² PENLTY SCORE PENLTY RMP 25 SETS 4 SETS 25 SETS 25 SETS 25 SETS 25 SETS 36 SETS 25 SETS RMP FLEX SETING FUTURE SETING PENLTY SCORE PENLTY FUTURE SETING FUTURE SETING RINK m² WTER ROOM Project Title: Client: This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: Date: Revisions/Issues: Sheet Title: Reviewed by: Checker Plot Date: 4//207 7:47:9 PM ISSUED FOR DP NORTH SURREY SPORTS & ICE CENTRE 08/9/09 #26 STREET, SURREY, BC THE CITY OF SURREY Level Plan uthor Project North: 0 0a m 44 9' 53" ICE MELT PIT ICE PLNT m² BOILER ROOM STORGE Not Enclosed Graphic Scale: Scale: : 200 Project No.: 267 Drawing No.: -0

24 G F E D C B CURVED ROOF ON GL ROOF LINE BOVE 684 West 2nd venue Vancouver BC V6J H4 CND a FLT ROOF W/ 2% SLOPE 2 2a OPEN TO BELOW YOG / STRETCHING ROOM m² SPIN ROOM m² WOMEN'S CHNGE ROOM MEN'S CHNGE ROOM Notes 3 WEIGHT ROOM m² ELEV. 3a MULTI PURPOSE ROOM m² 4 4a WOMEN'S BTHROOM MEN'S BTHROOM JN. 4 BRRIER FREE SETS 5 5a MULTI PURPOSE ROOM m² STORGE 37.3 m² 255 MOVBLE SETS 4 BRRIER FREE SETS 245 FIXED SETS 6a COMMUNITY BORDROOM 40.6 m² 4 BRRIER FREE SETS Revisions/Issues: ISSUED FOR DP 7 Project Title: NORTH SURREY SPORTS & ICE CENTRE 7a FUTURE CRU SPCE m² 4 BRRIER FREE SETS Client: #26 STREET, SURREY, BC THE CITY OF SURREY 8 8a EXIT STIR 2 Sheet Title: Level 2 Plan 9 FLT ROOF W/ 2% SLOPE RISED PLTFORM ELECTRICL BOILER ROOM SOUND BOOTH This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: uthor Project North: FLT ROOF W/ 2% SLOPE Reviewed by: Checker 9a Date: 2/2/6 Plot Date: 4//207 7:47:33 PM FLT ROOF W/ 2% SLOPE FLT ROOF W/ 2% SLOPE Graphic Scale: 0 0a Scale: : 200 Project No.: 267 Drawing No.: -02

25 G 2 F 3 E D 4 C B a %.9% 0.33% West 2nd venue Vancouver BC V6J H4 CND MECHNICL - SCREEN Notes 2a a 4 4a % 7.00% 0.20% 2.30% 22.0% 2.50% 0.20% 2.00% 8.00% 4.00% 5a a Revisions/Issues: Project Title: ISSUED FOR DP NORTH SURREY SPORTS & ICE CENTRE 7a #26 STREET, SURREY, BC Client: THE CITY OF SURREY Sheet Title: Roof Plan 8a This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: uthor Reviewed by: Checker Project North: 9a Date: 2/3/6 Plot Date: 4//207 7:49:9 PM Graphic Scale: 0 0a % 2.00% Scale: : 200 Project No.: 267 Drawing No.: -05

26 0a 0 9a 9 8a 8 7a 7 6a 6 5a 5 4a 4 3a 3 2a 2 a MTERIL LEGEND 0000 T.O. GLULM (U) T.O. GLULM (L) TPO- WD- TPO MET-2 MET- MET 2 KINGSPN METL PNEL DRK GREY MET 3 KINGSPN METL PNEL BEIGE GREY MET 4 METL FCI PINTED TO MTCH MET MET 5 METL DOOR LEF PINTED TO MTCH MET 2 MET 6 KINGSPN METL PNEL ZINC GREY WD GLULM CLER FINSIH GL CLER GLSS TPO TPO ROOFING MEMBRNE ST STOREFRONT MULLION PINTED MTCH MET PL POLYCRBONTE Level Level GL- 0 North -003 G F E D C B MET- T.O. GLULM (U) 3200 MET-3 T.O. GLULM (L) WD- MET-4 MET-4 Notes MET-5 : West 2nd venue Vancouver BC V6J H4 CND ST- MET KINGSPN METL PNEL LIGHT GREY WD Level 3 MET-4 MET-4 MET WD- MET-2 WD Level Level Level 0 2 MET-2 East MET- MET-5 MET-5 MET-3 : 200 a 2 2a 3 3a 4 4a 5 5a 6 6a 7 7a 8 8a 9 9a 0 0a 0000 T.O. GLULM (U) T.O. GLULM (L) TPO TPO- WD- HORIZONTL SCREEN MET-4 MET ISSUED FOR DP 6400 Level 3 Project Title: NORTH SURREY SPORTS & ICE CENTRE Revisions/Issues: Level 2 MET Level #26 STREET, SURREY, BC 0 3 South GL- MET-2 MET-3 MET- Client: : 200 B C D E F G THE CITY OF SURREY Sheet Title: Elevations T.O. GLULM (U) T.O. GLULM (L) MET-2 WD- MET MET- MET uthor Project North: MET Draw by: Reviewed by: Checker 6400 Level 3 This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. TPO- MET- ST- Level 2 Date: 2/3/6 Plot Date: 4//207 7:46:54 PM ST- Graphic Scale: Level MET-6 Scale: 0 4 West : 200 MET- MET-3 MET-2 ST- GL- ST- GL- Drawing No.: s indicated Project No.:

27 a 2 2a 3 3a 4 4a 5 5a 6 6a 7 7a 8 8a 9 9a 0 0a T.O. GLULM (U) 6400 T.O. GLULM (L) West 2nd venue Vancouver BC V6J H4 CND Level Level Notes Level 0 2 Section : 200 a 2 2a 3 3a 4 4a 5 5a 6 2 6a 7 7a 8 8a 9 3 9a 0 0a T.O. GLULM (U) 6400 T.O. GLULM (L) 3200 Level Level Level 0 3 Section 2 : 200 a 2 2a 3 3a 4 4a 5 5a 6 6a 7 7a 8 8a 9 9a 0 0a T.O. GLULM (U) 6400 T.O. GLULM (L) ISSUED FOR DP Level Level 2 Revisions/Issues: Project Title: NORTH SURREY SPORTS & ICE CENTRE 3675 Level 0 #26 STREET, SURREY, BC 4 Section 3 : 200 a a 3 3a 4 4a 5 5a a 7 7a 8 8a a 0 0a 2 3 Client: Sheet Title: THE CITY OF SURREY Building Sections T.O. GLULM (U) 6400 T.O. GLULM (L) 3200 This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: uthor Project North: Reviewed by: Checker Level Level Date: 2/3/6 Plot Date: 4//207 8:06:00 PM Graphic Scale: 3675 Level 0 Section 4 : 200 Scale: : 200 Project No.: 267 Drawing No.: -30

28 4 3 2 B C D E F G T.O. GLULM (U) West 2nd venue Vancouver BC V6J H4 CND T.O. GLULM (L) 3200 Level Notes Level Level 0 Section 6 : B C D E F G T.O. GLULM (U) 6400 T.O. GLULM (L) Level Level Level ISSUED FOR DP 2 Section 7 : B -30 C -30 D E-30 F -30 G Revisions/Issues: Project Title: NORTH SURREY SPORTS & ICE CENTRE #26 STREET, SURREY, BC T.O. GLULM (U) 6400 Client: THE CITY OF SURREY T.O. GLULM (L) 3200 Sheet Title: Building Section Level Level Level 0 This drawing as an instrument of service is the property of Walter Francl rchitecture Inc. and may not be reproduced without the firm's permission. ll information shown on the drawing is for the use in this specific project only and shall not be used otherwise without written permission from this office. Contractors shall verify and be responsible for all dimensions on the job and this office shall be informed of any discrepancies and variations shown on this drawing. Do no scale drawings. Draw by: Reviewed by: Checker Date: 2/3/6 uthor Plot Date: 4//207 8:03:07 PM Project North: Graphic Scale: 3 Section 8 : 200 Scale: : 200 Project No.: 267 Drawing No.: -303

29 TTCHMENT #2 CLOVERDLE SPORT & ICE COMPLEX SCHEMTIC DESIGN DRWINGS RFEOI/SOQ # for Pre-qualification for rena Refrigeration Plant System Contractor Page 7 of 8

30 CLOVERDLE SPORT & ICE COMPLEX

31 EXISTING SITE CONDITIONS Bill Reid Park and mphitheatre Skateboard Park Recreation Centre Cloverdale Curling Club Cloverdale rena Cloverdale Rodeo and Exhibition Food Services Shannon Hall BC Vintage Truck Museum and Old Town Hall griplex and Fairground Operations Parking Horseshoe Club Residential buffer zone Stables Stetson Bowl Stadium Lord Tweedsmuir School Harness racing track Outdoor community pool Greenaway Park CLOVERDLE SPORT & ICE COMPLEX

32 CONTEXT PLN : New intersection with 64th ave 77b street extension Sport & Ice Complex Parking lot (24 spaces) Future third arena expansion area New Millennium Stage loading Existing fairground ops building Relocated fariground ops building griplex Existing parking lot New intersection with 62nd ave CLOVERDLE SPORT & ICE COMPLEX

33 SITE PLN : Regraded and cleared park area with new grass seeding New naturalized planted area (refer to landscape dwgs) Potential public art location Covered entry plaza Drop off Fire route Barrier free parking (5) Short term parking (7) 220 parking spaces Multi use plaza/warm up area Regraded naturalized landscape zone Ice resurfacer loading and outdoor snow melt Future third rink New Millennium Stage loading area Total 232 parking spaces incl. BF and short term CLOVERDLE SPORT & ICE COMPLEX

34 00 LEVEL PLN :400 6,887 sqm (74,3 sqft) B UP Entry lobby Elevator Reception Skate shop Skaters lobby (capacity 250) Recycling & Janitorial Men s washroom Women s washroom Team change room (8) Half-size change room (8) Official s change room Janitor s room Rink equipment storage Servery Servery storage Vending alcove Cafe seating IT room Staff open office Staff meeting room Break room Office Staff change room Safe room & Security Office Skate shop storage Workshop Foreman s office Staff washroom Ice resurfacers storage Ice resurfacers entry/exit Ice manufacturing Electrical room Sprinkler room Mechanical Room CLOVERDLE SPORT & ICE COMPLEX

35 200 LEVEL PLN :400,597 sqm (7,89 sqft) B DN B Mezzanine Elevator lobby Elevator room Mechanical room Recessed mechanical roof Men s washroom Women s washroom Janitor s room Universal washroom Exit stair Bleachers (200) Community board room (24) Multipurpose room (59) Multipurpose room (32) Multipurpose room storage MP room terrace Storage TOTL RE 8,484 sqm (9,32 sqft) CLOVERDLE SPORT & ICE COMPLEX

36 ENLRGED PLNS Back of House Plan :200 Change Rooms Plan : Reception Skate shop Elevator Safe room IT room Open office Skate shop storage Meeting room (0) Break room Office Staff change room Security Office Workshop Ice resurfacer storage Foreman s office Staff washroom Ice resurfacer exterior access Ice manufacturing Change room entry/stick rack Change room Grooming counter Barrier free W/C Shower stall Barrier free shower stall Official s change room Large Change Rooms Bench Space 52 LF Small Change Rooms Bench Space 22 LF CLOVERDLE SPORT & ICE COMPLEX

37 Section (rena) ve rena Bleachers Locker room Team washrooms Mezzanine Covered entry plaza Parking Section B (Back of house and lobby) Ice manufacturing Rooftop mechanical Ice resurfacers Staff offices Mechanical room Reception/skate shop Lobby CLOVERDLE SPORT & ICE COMPLEX

38 ELEVTIONS :400 North South West East CLOVERDLE SPORT & ICE COMPLEX

39 CLOVERDLE SPORT & ICE COMPLEX

40 CLOVERDLE SPORT & ICE COMPLEX

41 CLOVERDLE SPORT & ICE COMPLEX

42 CLOVERDLE SPORT & ICE COMPLEX